Blanchardstown Interchange - Integrated Delivery Support Services Partner (IDSSP)

The National Transport Authority (NTA) on behalf of Blanche Developments Limited (BDL) is procuring an Integrated Delivery Support Service Partner (IDSSP) who will be a multi-disciplinary engineering consultant, to support and supervise the design and construction of the 'Blanchardstown Interchange Works’ (BIW) (including a Bus Plaza) to be constructed under …

CPV: 71500000 Construction-related services, 79416200 Public relations consultancy services, 71313410 Risk or hazard assessment for construction, 70332100 Land management services, 70122200 Land purchase services, 71313100 Noise-control consultancy services, 71200000 Architectural and related services, 71242000 Project and design preparation, estimation of costs, 71324000 Quantity surveying services, 71334000 Mechanical and electrical engineering services, 71312000 Structural engineering consultancy services, 71311210 Highways consultancy services, 71311100 Civil engineering support services, 71530000 Construction consultancy services, 71540000 Construction management services, 71541000 Construction project management services, 79933000 Design support services, 71320000 Engineering design services, 71244000 Calculation of costs, monitoring of costs, 71318000 Advisory and consultative engineering services, 71311220 Highways engineering services, 71311200 Transport systems consultancy services, 71311300 Infrastructure works consultancy services, 71311000 Civil engineering consultancy services, 71631480 Road-inspection services, 71322500 Engineering-design services for traffic installations, 79415200 Design consultancy services, 71317210 Health and safety consultancy services
Deadline:
Jan. 24, 2025, noon
Deadline type:
Submitting a bid
Place of execution:
Blanchardstown Interchange - Integrated Delivery Support Services Partner (IDSSP)
Awarding body:
National Transport Authority_1149
Award number:
0

1. Buyer

1.1 Buyer

Official name : National Transport Authority_1149
Legal type of the buyer : Body governed by public law
Activity of the contracting authority : General public services
Activity of the contracting entity : Urban railway, tramway, trolleybus or bus services

2. Procedure

2.1 Procedure

Title : Blanchardstown Interchange - Integrated Delivery Support Services Partner (IDSSP)
Description : The National Transport Authority (NTA) on behalf of Blanche Developments Limited (BDL) is procuring an Integrated Delivery Support Service Partner (IDSSP) who will be a multi-disciplinary engineering consultant, to support and supervise the design and construction of the 'Blanchardstown Interchange Works’ (BIW) (including a Bus Plaza) to be constructed under a design-and-build type contract. While the procurement process will be conducted by the NTA, the contracting party will ultimately be BDL (either by way of novation of the contract by the NTA or by direct entry into contract by BDL). Whilst it is intended that the BIW will be constructed under a design-and-build contract, the IDSSP will develop the design of the Bus Plaza element of BIW and prepare the detailed scope of work for inclusion in the tender documents for the procurement of a construction contractor, as an employer designed element of the construction contract. The IDSSP will manage the tendering process for procurement of services of the construction contractor, oversee the delivery of infrastructure works and supervise the performance of the construction contractor. The IDSSP shall support and provide technical expertise across the following functions including but not limited to: Civil Engineering Design; Architectural Design; Design and Engineering Assurance; Act as Employers Representative; Delivery Planning and Integration; Construction Assurance; Construction Supervision; Procurement Support; Project Controls; Project Management; Performance and Reporting; Scheduling and Resourcing; Risk Management; Cost Control and Management; Change Control and Management; Stakeholder Engagement and Communication; Development of construction sequencing strategy to minimise the disruption to residents, businesses and commuters; Prepare the scope of work for accommodation works for properties affected by the BIW; Produce a preliminary traffic management plan; Land and property acquisition and management; Consents and Third-Party Agreements; Information Management and Systems; implementation of BIM and other digital construction approaches; Health, Safety, Environment and Quality; Sustainability, Efficiency, and Innovation; Governance and Project Assurance; Learning and Knowledge Management; Facilities Management; and Building Control. BIW comprises of infrastructure improvements for active travel (both walking and cycling) and the provision of enhanced bus priority measures for existing and future service users on both public and private land at Blanchardstown Town Centre, Dublin 15. The works will commence at the south end of the Blanchardstown Road North bridge over the N3 at junction 3 (Blanchardstown / Mulhuddart)and proceed along the R121 (Blanchardstown Road South) into the Blanchardstown Town Centre. From a new bus plaza to the north-west of Blanchardstown Town Centre, the works will continue towards and terminate at the Snugborough Road junction. The Bus Plaza is an important element of BIW and comprises of a physical bus interchange and driver welfare facility structure in the Blanchardstown Interchange. BIW (including the bus plaza) forms part of the Blanchardstown to City Centre Core Bus Corridor Scheme, within the BusConnects Dublin Core Bus Corridor Infrastructure Works (“CBCIW”). The CBCIW are being delivered by the National Transport Authority to provide approximately 230km of bus priority and approximately 200km of cycle routes across Dublin and the Greater Dublin Area. The key objectives of CBCIW are to enhance the capacity and potential of the public transport system, enhance the potential for cycling by providing safe infrastructure for cycling, support the delivery of an efficient, low carbon and climate resilient public transport service and enable compact growth, regeneration opportunities and improve accessibility.
Procedure identifier : 5dedbbab-81c8-4d32-a668-ef2e2db7b6b3
Type of procedure : Negotiated with prior publication of a call for competition / competitive with negotiation
The procedure is accelerated : no
Justification for the accelerated procedure :
Main features of the procedure :

2.1.1 Purpose

Main nature of the contract : Services
Main classification ( cpv ): 71500000 Construction-related services
Additional classification ( cpv ): 79416200 Public relations consultancy services
Additional classification ( cpv ): 71313410 Risk or hazard assessment for construction
Additional classification ( cpv ): 70332100 Land management services
Additional classification ( cpv ): 70122200 Land purchase services
Additional classification ( cpv ): 71313100 Noise-control consultancy services
Additional classification ( cpv ): 71200000 Architectural and related services
Additional classification ( cpv ): 71242000 Project and design preparation, estimation of costs
Additional classification ( cpv ): 71324000 Quantity surveying services
Additional classification ( cpv ): 71334000 Mechanical and electrical engineering services
Additional classification ( cpv ): 71312000 Structural engineering consultancy services
Additional classification ( cpv ): 71311210 Highways consultancy services
Additional classification ( cpv ): 71311100 Civil engineering support services
Additional classification ( cpv ): 71530000 Construction consultancy services
Additional classification ( cpv ): 71540000 Construction management services
Additional classification ( cpv ): 71541000 Construction project management services
Additional classification ( cpv ): 79933000 Design support services
Additional classification ( cpv ): 71320000 Engineering design services
Additional classification ( cpv ): 71244000 Calculation of costs, monitoring of costs
Additional classification ( cpv ): 71318000 Advisory and consultative engineering services
Additional classification ( cpv ): 71311220 Highways engineering services
Additional classification ( cpv ): 71311200 Transport systems consultancy services
Additional classification ( cpv ): 71311300 Infrastructure works consultancy services
Additional classification ( cpv ): 71311000 Civil engineering consultancy services
Additional classification ( cpv ): 71631480 Road-inspection services
Additional classification ( cpv ): 71322500 Engineering-design services for traffic installations
Additional classification ( cpv ): 79415200 Design consultancy services
Additional classification ( cpv ): 71317210 Health and safety consultancy services

2.1.2 Place of performance

Anywhere

2.1.3 Value

Estimated value excluding VAT : 4 500 000 Euro

2.1.4 General information

Legal basis :
Directive 2014/25/EU

2.1.5 Terms of procurement

Terms of submission :
Maximum number of lots for which one tenderer can submit tenders : 0

5. Lot

5.1 Lot technical ID : LOT-0001

Title : Blanchardstown Interchange - Integrated Delivery Support Services Partner (IDSSP)
Description : The National Transport Authority (NTA) on behalf of Blanche Developments Limited (BDL) is procuring an Integrated Delivery Support Service Partner (IDSSP) who will be a multi-disciplinary engineering consultant, to support and supervise the design and construction of the 'Blanchardstown Interchange Works’ (BIW) (including a Bus Plaza) to be constructed under a design-and-build type contract. While the procurement process will be conducted by the NTA, the contracting party will ultimately be BDL (either by way of novation of the contract by the NTA or by direct entry into contract by BDL). Whilst it is intended that the BIW will be constructed under a design-and-build contract, the IDSSP will develop the design of the Bus Plaza element of BIW and prepare the detailed scope of work for inclusion in the tender documents for the procurement of a construction contractor, as an employer designed element of the construction contract. The IDSSP will manage the tendering process for procurement of services of the construction contractor, oversee the delivery of infrastructure works and supervise the performance of the construction contractor. The IDSSP shall support and provide technical expertise across the following functions including but not limited to: Civil Engineering Design; Architectural Design; Design and Engineering Assurance; Act as Employers Representative; Delivery Planning and Integration; Construction Assurance; Construction Supervision; Procurement Support; Project Controls; Project Management; Performance and Reporting; Scheduling and Resourcing; Risk Management; Cost Control and Management; Change Control and Management; Stakeholder Engagement and Communication; Development of construction sequencing strategy to minimise the disruption to residents, businesses and commuters; Prepare the scope of work for accommodation works for properties affected by the BIW; Produce a preliminary traffic management plan; Land and property acquisition and management; Consents and Third-Party Agreements; Information Management and Systems; implementation of BIM and other digital construction approaches; Health, Safety, Environment and Quality; Sustainability, Efficiency, and Innovation; Governance and Project Assurance; Learning and Knowledge Management; Facilities Management; and Building Control. BIW comprises of infrastructure improvements for active travel (both walking and cycling) and the provision of enhanced bus priority measures for existing and future service users on both public and private land at Blanchardstown Town Centre, Dublin 15. The works will commence at the south end of the Blanchardstown Road North bridge over the N3 at junction 3 (Blanchardstown / Mulhuddart)and proceed along the R121 (Blanchardstown Road South) into the Blanchardstown Town Centre. From a new bus plaza to the north-west of Blanchardstown Town Centre, the works will continue towards and terminate at the Snugborough Road junction. The Bus Plaza is an important element of BIW and comprises of a physical bus interchange and driver welfare facility structure in the Blanchardstown Interchange. BIW (including the bus plaza) forms part of the Blanchardstown to City Centre Core Bus Corridor Scheme, within the BusConnects Dublin Core Bus Corridor Infrastructure Works (“CBCIW”). The CBCIW are being delivered by the National Transport Authority to provide approximately 230km of bus priority and approximately 200km of cycle routes across Dublin and the Greater Dublin Area. The key objectives of CBCIW are to enhance the capacity and potential of the public transport system, enhance the potential for cycling by providing safe infrastructure for cycling, support the delivery of an efficient, low carbon and climate resilient public transport service and enable compact growth, regeneration opportunities and improve accessibility.
Internal identifier : 0

5.1.1 Purpose

Main nature of the contract : Services
Main classification ( cpv ): 71500000 Construction-related services
Additional classification ( cpv ): 79416200 Public relations consultancy services
Additional classification ( cpv ): 71313410 Risk or hazard assessment for construction
Additional classification ( cpv ): 70332100 Land management services
Additional classification ( cpv ): 70122200 Land purchase services
Additional classification ( cpv ): 71313100 Noise-control consultancy services
Additional classification ( cpv ): 71200000 Architectural and related services
Additional classification ( cpv ): 71242000 Project and design preparation, estimation of costs
Additional classification ( cpv ): 71324000 Quantity surveying services
Additional classification ( cpv ): 71334000 Mechanical and electrical engineering services
Additional classification ( cpv ): 71312000 Structural engineering consultancy services
Additional classification ( cpv ): 71311210 Highways consultancy services
Additional classification ( cpv ): 71311100 Civil engineering support services
Additional classification ( cpv ): 71530000 Construction consultancy services
Additional classification ( cpv ): 71540000 Construction management services
Additional classification ( cpv ): 71541000 Construction project management services
Additional classification ( cpv ): 79933000 Design support services
Additional classification ( cpv ): 71320000 Engineering design services
Additional classification ( cpv ): 71244000 Calculation of costs, monitoring of costs
Additional classification ( cpv ): 71318000 Advisory and consultative engineering services
Additional classification ( cpv ): 71311220 Highways engineering services
Additional classification ( cpv ): 71311200 Transport systems consultancy services
Additional classification ( cpv ): 71311300 Infrastructure works consultancy services
Additional classification ( cpv ): 71311000 Civil engineering consultancy services
Additional classification ( cpv ): 71631480 Road-inspection services
Additional classification ( cpv ): 71322500 Engineering-design services for traffic installations
Additional classification ( cpv ): 79415200 Design consultancy services
Additional classification ( cpv ): 71317210 Health and safety consultancy services

5.1.2 Place of performance

Anywhere
Additional information :

5.1.3 Estimated duration

Other duration : Unknown

5.1.4 Renewal

Maximum renewals : 1

5.1.5 Value

Estimated value excluding VAT : 4 500 000 Euro

5.1.6 General information

Reserved participation : Participation is not reserved.
Procurement Project not financed with EU Funds.
The procurement is covered by the Government Procurement Agreement (GPA) : yes

5.1.7 Strategic procurement

Aim of strategic procurement : No strategic procurement

5.1.9 Selection criteria

Criterion :
Type : Other

5.1.11 Procurement documents

Languages in which the procurement documents are officially available : English
Languages in which the procurement documents (or their parts) are unofficially available : English
Deadline for requesting additional information : 10/01/2025 14:00 +00:00

5.1.12 Terms of procurement

Terms of submission :
Electronic submission : Required
Languages in which tenders or requests to participate may be submitted : English
Electronic catalogue : Not allowed
Tenderers may submit more than one tender : Not allowed
Deadline for receipt of tenders : 24/01/2025 12:00 +00:00
Terms of contract :
The execution of the contract must be performed within the framework of sheltered employment programmes : No
Conditions relating to the performance of the contract : See Procurement documents
Financial arrangement : See procurement documents

5.1.15 Techniques

Framework agreement :
No framework agreement
Information about the dynamic purchasing system :
No dynamic purchase system
Electronic auction : no

5.1.16 Further information, mediation and review

Review organisation : The High Court of Ireland
Organisation providing additional information about the procurement procedure : National Transport Authority_1149
Organisation providing offline access to the procurement documents : National Transport Authority_1149
Organisation receiving requests to participate : National Transport Authority_1149
Organisation processing tenders : National Transport Authority_1149
TED eSender : European Dynamics S.A.

8. Organisations

8.1 ORG-0001

Official name : National Transport Authority_1149
Registration number : National Transport Authority
Postal address : Haymarket House Building, 54 Smithfield, Arran Quay
Town : Dublin
Postcode : D07 CF98
Country subdivision (NUTS) : Dublin ( IE061 )
Country : Ireland
Telephone : +353 1 8798300
Roles of this organisation :
Buyer
Organisation providing additional information about the procurement procedure
Organisation providing offline access to the procurement documents
Organisation receiving requests to participate
Organisation processing tenders

8.1 ORG-0002

Official name : The High Court of Ireland
Registration number : The High Court of Ireland
Department : The High Court of Ireland
Postal address : Four Courts, Inns Quay, Dublin 7
Town : Dublin
Postcode : D07 WDX8
Country subdivision (NUTS) : Dublin ( IE061 )
Country : Ireland
Telephone : +353 1 8886000
Roles of this organisation :
Review organisation

8.1 ORG-0003

Official name : European Dynamics S.A.
Registration number : 002024901000
Department : European Dynamics S.A.
Town : Athens
Postcode : 15125
Country subdivision (NUTS) : Βόρειος Τομέας Αθηνών ( EL301 )
Country : Greece
Telephone : +30 2108094500
Roles of this organisation :
TED eSender

11. Notice information

11.1 Notice information

Notice identifier/version : cddf11c9-8649-455d-acd9-c8943d32c11c - 01
Form type : Competition
Notice type : Contract or concession notice – standard regime
Notice dispatch date : 29/11/2024 16:54 +00:00
Languages in which this notice is officially available : English

11.2 Publication information

Notice publication number : 00736577-2024
OJ S issue number : 235/2024
Publication date : 03/12/2024